Amendments to JCT Minor Works Building Contract with Contractor’s Design 2011 Articles of Agreement CEBC Notes This Agreement is made the
Between
20
To be completed by CEBC Legal.
The Employer Cheshire East Borough Council
(Company No.
)
of/ whose registered office is at Westfields, Middlewich Road, Sandbach CW11 1HZ
And
The Contractor
To be completed post contract award
(Company No. of/ whose registered office is at
1
)
Recitals CEBC Notes
Whereas First
The Employer wishes to have the following work carried out
Clearance and strip out of existing Gift Shop, together with design and construction of shop fitting works, including all labour, plant and materials required for refurbishment, adaptation and modifications. Delete as Appropriate at
Tatton Park, Knutsford, Cheshire WA16 6QN. (“the Works”) Under the direction of the Architect/ Contract Administrator referred to in Article3;
Second
the Works include the design and construction of
Insert contractor designed elements
1. Display cabinets / cupboards / wall fixtures / shelving / tables / etc. 2. Till point / wrapping station 3. Seasonal alcove 4. Room lighting / display lighting 5. Power supplies 6. HVAC 7. Mirrors 8. Flooring 9. Blinds 10. Misc joinery 11. Painting and decorating
(“!the Contractor’s Designed Portion”) Third
the Employer has had the following documents prepared which show and describe the work to be done:
Recommendations report prepared by Metamorphosis Group entitled ‘Tatton Park Gift Shop’ (un-referenced and un-dated). Delete as Appropriate the drawings numbered/ listed in
Drawing entitled ‘Gift Shop – existing floor
2
plan and internal wall elevations’. Various concept drawings included in Metamorphosis report.
(“the Contract Drawings) a Specification (“the Contract Specification”) Work Schedules other documents showing or describing or otherwise stating his requirements for the design and construction of the Contractor’s Designed Portion (“the Employers Requirements”)
Project Requirements document Fourth
The Contractor has supplied the Employer with a copy of the priced Contract Specification or Work Schedules or provided a Schedule of Rates
3
Delete as Appropriate
Articles Now it is hereby agreed as follows Article 3: Architect/ Contract Administrator
CEBC Notes
For the purposes of this Contract the Architect/ Contract Administrator is
Graham Jones of
To be inserted
Cheshire East Council
Article 4: CDM Coordinator
The CDM Co-ordinator for the purposes of the CDM Regulations is the Architect/ Contract Administrator (or)
Not applicable of
4
To be inserted
Articles (Cont’d) CEBC Notes Article 5: Principal Contractor
The Principal Contractor for the purpose of the CDM regulations is the Contractor To be inserted
(or)
Not applicable of
Article 6: Adjudication
If any dispute or difference arises under this Contract either Party may refer it to adjudication in accordance with clause 7.2
Article 7: Arbitration
Where Article 7 Applies, the, subject to article 6 and the exceptions set out below, and dispute or difference between the Parties of any kind whatsoever arising out of or in connection with this Contract shall be referred to arbitration in accordance with Schedule 1 and the JCT 2011 edition of the Construction Industry Model Arbitration Rules (CIMAR).
5
Adjudication Applies
Arbitration does not apply
Contract Particulars Clause etc.
Subject
CEBC Notes
Fifth Recital and Schedule 2 (paragraphs 1.1, 1.2, 1.5, 1.6, 2.1 and 2.2)
Base Date
10 days before the date for return of tenders
Fifth Recital and clause 4.2
Construction Industry Scheme (CIS)
Employer at the Base Date is a ‘contractor’ / is not a ‘contractor’ for the purposes of the CIS
Sixth Recital
CDM Regulations
The project is / is not notifiable
Seventh Recital
Framework Agreement
N/A1st December 2010 Low Value Contractors Framework Cheshire East Borough Council
Eighth Recital and Schedule 3
Supplementary Provisions
Collaborative Working
Paragraph 1 applies / does not apply
Health and safety
Paragraph 2 applies / does not apply
Cost savings and value improvements
Paragraph 3 applies / does not apply
Sustainable development and environmental considerations
Paragraph 4 applies / does not apply
Performance Indicators and monitoring
Paragraph 5 applies / does not apply
Notification and negotiation of disputes
Paragraph 6 applies / does not apply
6
Delete as appropriate
Contract Particulars (Cont’d) Clause etc.
Subject Where paragraph 6 applies, the respective nominees of the Parties are
CEBC Notes Employer’s nominee Peter Broughton Graham Jones Contractor’s nominee
Or such replacement as each Party may notify to the other from time to time Article 7
Arbitration
Article 7 and Schedule 1 (Arbitration) apply / do not apply
1.1
CDM Planning Period
Shall mean the period of
To be completed post Contract Award, as named in the Framework Agreement
Number of Days or Weeks to be inserted
____N/A______*days / weeks ending on the Date for Commencement of the Works / beginning / ending on _______N/A_________20___ 2.3
Date for Commencement of the Works
Insert date when if known
2.3
Date for Completion
Insert date when if known or time period
2.9
Liquidated damages
at the rate of £ nil per______
Generally not used, but may be required on specific projects
2.11
Rectification Period
12 months from the date of practical completion
4.3
Percentage of the total value of work etc.
100 per cent
Generally retention not held
4.4
Percentage of the total amount to be paid to the Contractor
100 per cent
Generally retention not held
7
Contract Particulars (Cont’d) Clause etc.
Subject
4.8.1
Supply of documentation for computation of amount to be finally certified
1 months from the date of practical completion
4.11 and Schedule 2
Contribution, levy and tax changes
Schedule 2 (Fluctuations Option) applies
4.11 and Schedule 2 (paragraph 13)
Percentage addition for Fluctuations Option
___________ per cent
5.3.2
Contractor’s insurance: injury to persons or property – insurance cover
£ 10,000,000.00
Insurance of the Works etc. – alternative provisions
Clause 5.4A (Works insurance by Contractor in Joint Names) applies/
5.4A, 5.4B and 5.4C
CEBC Notes
£5,000,000.00
Clause 5.4B (Works and existing structures insurance by Employer in Joint Names) applies/
If project is a new building then clause 5.4A will apply and 5.4B should be deleted.
Clause 5.4C (Existing structures insurance by Employer in own Name) applies/ 5.4A.1 and 5.4B.1.2
Percentage to cover professional fees
15 per cent
7.2
Adjudication
The adjudicator is to be nominated
Nominating body – where no Adjudicator is named or where the named Adjudicator is unwilling or unable to act
Royal Institute of British Architects The Royal Institution of Chartered surveyors constructionadjudicators.com Association of Independent Construction Adjudicators Chartered Institute of Arbitrators
Schedule 1 (paragraph 2.1)
Arbitration – appointer of Arbitrator (and of any replacement)
President or a Vice-President: Royal Institute of British Architects The Royal Institution of Chartered surveyors Chartered Institute of Arbitrators
8
Check 15% is sufficient
Amendments to the Standard Conditions of Contract Amendment 1 Schedule 3 – Supplemental Provisions Clause 5.1 – Delete “Contract Documents” in the 2 Agreement”.
nd
line and replace with “Framework
Amendment 2 Add new Clause 2.1.7 – “Collateral Warranties to be provided for all sub-consultants and sub-contractors with design responsibilities within two weeks of entering into a subcontract. Collateral Warranties to be in a format to be agreed.”
9